Terms of Service

This page governs your use of www.akhileshenterprises.com and the information published on it. It is a website terms page.

Any actual work we carry out is governed by the written quotation and work order signed for that project. Where anything on this website differs from your signed quotation or work order, the signed document wins. Nothing on this site — including prices, timelines, service descriptions or photographs — forms a contractual offer on its own.

Quotations are estimates prepared from the information available at the time. Unless the quotation states otherwise, it is valid for 30 days from its date and is subject to a physical site survey.

Where a quotation was prepared from photographs, drawings or a description over the phone, quantities and scope may change once we see the site. If they do, we tell you in writing before starting, and you decide whether to proceed.

Additional work requested after the quotation is accepted — extra rooms, a changed finish, additional coats, discovered damage — is chargeable and will be confirmed in writing as a variation before we carry it out.

Our projects are normally structured as an advance on confirmation, one or more stage payments as the work progresses, and a balance on completion and handover. The proportions vary with the size and length of the job.

The actual payment terms for your project are the ones written in your work order. Please read them there rather than relying on this summary. Materials specified as client-supplied are not included in our price. Government taxes apply as stated on the invoice.

We warrant our workmanship for the period stated in your quotation. Within that period we return and put right defects that arise from how we did the work — for example peeling caused by inadequate surface preparation, or a polish finish that fails prematurely.

The workmanship warranty does not cover:

• Normal wear, fading from sunlight, or aging of the finish
• Damage from water ingress, structural movement, leakage or seepage originating outside the area we worked on
• Damage caused by others, by cleaning with unsuitable chemicals, or by misuse
• Work carried out over surfaces or substrates you instructed us not to prepare
• Materials that you supplied

Paints, polishes, laminates, hardware, electrical fittings and similar goods carry the manufacturer’s warranty, not ours. Asian Paints, Berger, Nerolac, Hettich, Hafele and other brands set their own terms, durations and claim procedures.

We will tell you what was used, keep the relevant documentation where it is issued, and help you raise a claim. We cannot extend or substitute for a manufacturer’s warranty.

To work safely and to schedule, we need the following from the client:

• Site access during agreed working hours, including keys or a person on site to open up.
• Water and electricity at the site, at your cost, for preparation, machinery and cleaning.
• Valuables cleared. Please remove jewellery, cash, documents, electronics, artwork and anything fragile or irreplaceable before we start. We sheet and protect what remains, but we cannot accept responsibility for valuables left in the work area.
• Society or building permissions — work permits, lift usage, approved working hours, debris disposal rules, deposits and any noise restrictions. These are the client’s responsibility to obtain unless the work order says we will handle them.
• Decisions on time — shade selection, hardware choices and approvals. Delays in these shift the completion date.

Completion dates are our honest working estimate, not a guarantee. Exterior painting, waterproofing, polishing and spray work all depend on dry surfaces and controlled humidity.

Mumbai monsoon delays are expected and are not a breach of contract. The same applies to other events outside our control: society restrictions, power or water cuts, material supply failures, government orders, and access being denied on the day. Where a delay occurs we tell you promptly and agree a revised schedule; no penalty applies for delay from these causes unless your work order specifically provides one.

You may cancel before work starts. Where we have already incurred cost — materials bought or cut to your specification, custom furniture in production, crew mobilised, scaffolding erected — those costs are payable, and the balance of any advance is refunded.

If you cancel after work has begun, you pay for the work completed to that point plus committed materials, assessed fairly against the quotation.

We may stop work and withdraw where the site is unsafe, where agreed payments are overdue, or where required permissions turn out not to be in place. We will give you notice and the reason in writing.

We carry responsibility for damage we cause through our own negligence, and we will put it right or make it good.

To the fullest extent permitted by law, our total liability arising out of any project is limited to the total amount paid to us for that project. We are not liable for indirect or consequential loss — including loss of business, loss of rent, loss of profit, or hotel and relocation costs arising from a delay.

Nothing here limits liability for death or personal injury caused by negligence, or for fraud, or for anything else that cannot lawfully be limited.

The website itself is provided as-is. We keep it accurate but do not warrant that it is error-free or continuously available, and we are not liable for loss arising from reliance on the website alone rather than on a written quotation.

All text, photographs, drawings and design on this website are the property of Akhilesh Enterprises and may not be copied, republished or used in another business’s marketing without our written permission.

Photographs of completed work: unless you tell us otherwise in writing, we may photograph work we have completed and use those images in our portfolio, website, social media and printed materials. We do not publish your name, your address or identifying details with them. If you would rather we did not photograph your site at all, tell us before work starts and we will note it on the work order. If an image is already published and you want it removed, email akhileshenterprises545@gmail.com and we will take it down.

Client and brand names mentioned on this site are used descriptively to indicate work we have carried out. No endorsement by those parties is claimed or implied, and their trademarks remain their own.

These terms, and any contract for work, are governed by the laws of India and the State of Maharashtra. The courts at Thane, Maharashtra have exclusive jurisdiction over any dispute.

Before going to court, we ask that you raise the issue with us directly. Most disputes in this trade come from a misunderstanding of scope, and most are settled with a site visit.

We may update this page. The version in force for your project is the one published when your work order was signed, together with that work order.

Akhilesh Enterprises
Shop No. 04, Sai Mahal Building, RNP Park, Near Maruti Mandir, Bhayandar East, Thane, Maharashtra, 401105
+91 98196 56066
akhileshenterprises545@gmail.com